Legal Notice
ADVERTISEMENT FOR BIDS
HVAC REPLACEMENT FOR PERRY COUNTY SCHOOLS FOR THE PERRY COUNTY BOARD OF EDUCATION MARION, ALABAMA PROJECT #22-268
Sealed proposals as described above will be received by Dr. Marcia Smiley, Superintendent, at the Perry County Board of Education, 200 W. Monroe Street, Marion, AL 36745, Phone: 334-683-4144, until 2:00 PM Central Time, Thursday, May 18, 2023, then opened and read aloud.
There shall be a Non-Mandatory Prebid walkthrough on Wednesday, May 10, at 9:00 AM Central Time, starting at the School Board Office and proceeding to the schools.
All Bidders shall have general liability and workman’s compensation insurance. The project shall be bid excluding taxes. Separate bids must be submitted on proposal form furnished by the Architect or copies thereof. No bid may be withdrawn after scheduled closing for receipt of bids for a period of ninety (90) days. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owners judgment, the best interests of the Owner will thereby be promoted.
A certified check or Bid Bond payable to the Perry County Board of Education in an amount not less than five percent (5%) of the amount of the bid, but in no event more than $10,000.00 must accompany the bidder’s proposal if over $50,000.00 dollars. Performance and statutory labor and material payment bonds will be required at the signing of the Contract.
All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect. All bidders shall show such evidence by clearly displaying current license number on the outside of the sealed envelope in which the proposal is delivered.
PDFs of the project can be reviewed by going to the McKee website @ HYPERLINK “http://www.mckeeassoc.com/ “www.mckeeassoc.com and selecting “Project Bid List”. Also, if you are not receiving NOTIFICATIONS from us, please register on our website, “Project Bid List” by selecting manage your bid list profile. The documents may be viewed on-line and printed by General Contractors, Sub-Contractors and Suppliers. Documents published through this procedure are the only documents endorsed by the Architect. The Architect is unable to monitor, confirm and maintain other websites that provide documents. Addendums will be provided to entities that have CONFIRMED bidding for this particular project. The Architect retains ownership and copyrights of the documents. If bidders require printed sets, please submit request to the Architect at HYPERLINK “mailto:mckeeplans@gmail.co m”mckeeplans@gmail.com. Include your first & last name, company name, address, phone number and the project name and number. Print sets are to be returned in reusable condition within ten days after bid opening.
All RFIs and RFAs regarding the bid documents shall be sent and addressed through emails found on the RFI and RFA forms in the project manual. NOTE: ONLY THE RFI AND RFA FORMS IN THE PROJECT MANUAL WILL BE ACCEPTED. The Architect will not accept inquiries via telephone or fax.
Completion Time: See Scope of Work Section in Project Manual.
Supervision: Contractor to ensure proper supervision of all work.
Owner: Dr. Marcia Smiley, Superintendent, Perry County Board of Education, 200 Monroe Street, Marion, AL 36756, Phone: (334) 683-6528 Architect: McKee and Associates Architects, Inc., 631 South Hull Street, Montgomery, Alabama 36104, Phone: (334) 834-9933 5-4-3c
Legal Notice
NOTICE TO CREDITORS OF ESTATE OF LOUIRA HAMBRIGHT
LETTERS OF ADMINISTRATION of said deceased having been granted to LaKya Hunter on the 27th day of April, 2023, by the Honorable Arthur Crawford, Judge of Probate of Hale County, Alabama, notice is hereby given that all persons having claims against said estate are hereby required to present the same within time allowed by law or the same will be barred.
ALEXANDER F. BRASWELL
Attorney for Administrator
5-4-3c
Legal Notice
IN THE JUVENILE COURT OF HALE COUNTY, ALABAMA
IN RE: THE MATTER OF PIERCE DAMIAN, CASE NO. JU-2020-53.02 PIERCE HAILEY,CASE NO. JU-2020-54.02 minor children
NOTICE OF PETITON FOR TERMINATION OF PARENTAL RIGHTS TO: Ronnie James Pierce, II, father of Hailey Lynn Pierce and Damian Cain Pierce You are hereby given notice that a petition has been filed by the Hale County Department of Human Resources requesting your paternal rights be terminated to Hailey Lynn Pierce, born September 12, 2017, in Bessemer, Alabama, and Damian Cain Pierce, born on October 8, 2018, in Bessemer, Alabama. You are hereby given notice that you are required to file an answer with the Clerk of the Juvenile Court and with the Petitioner’s attorney, Walter A. Griess, Post Office Box 528, Eutaw, Alabama 35462, within fourteen (14) days of the date of the last publication of this notice or a default judgment can be entered against you. A final hearing may be held within ninety (90) days after the last day of this publication. You have been appointed Erica Kemmer as your attorney in this matter. Her office is located at 11 2nd Avenue, Moundville, Alabama, 35474. Her office number is (205) 450-9185.
Catrinna Long- Perry CIRCUIT CLERK
5-4-4c
Legal Notice
Notice to Contractors Federal Aid Project No. STPAAFMGR-0025(566) HALE COUNTY, ALABAMA
Sealed bids will be received by the Director of Transportation at the office of the Alabama Department of Transportation, Montgomery, Alabama until 10:00 AM on May 26, 2023 and at that time publicly opened for constructing the Resurfacing (Micro-Surfacing Seal Coat, Type II and Scrub Seal) and Traffic Stripe on SR- 25 from the junction of CR-85 to the Bibb County Line. Length 7.093 mi.
The total amount of uncompleted work under contract to a contractor must not exceed the amount of his or her qualification certificate.
The Entire Project Shall Be Completed In Thirty-five (35) Working Days. A 0.50% DBE Contract Obligation Is Required.
A Bidding Proposal may be purchased for $5.00. Plans may be purchased for $5.00 per set. Plans and Proposals are available at the Alabama Department of Transportation, 1409 Coliseum Boulevard, Room E- 108, Montgomery, AL 36110. Checks should be made payable to the Alabama Department of Transportation. Plans and Proposals will be mailed only upon receipt of remittance. No refunds will be made.
Minimum wage rates for this project have been pre-determined by the Secretary of Labor and are set forth in the advertised specifications. This project is subject to the contract work hours and Safety Standards Act and its implementing regulations.
Cashier’s check or bid bond for 5% of bid (maximum – $50,000.00) made payable to the Alabama Department of Transportation must accompany each bid as evidence of good faith.
The bracket range is shown only to provide general financial information to contractors and bonding companies concerning the project’s complexity and size. This Bracket should not be used in preparing a bid, nor will this bracket have any bearing on the decision to award this contract.
The Bracket Estimate On This Project Is From $1,195,688 To $1,461,396 .
The proposed work shall be performed in conformity with the rules and regulations for carrying out the Federal Highway Act.
Plans and Specifications are on file in Room E-108 of the Alabama Department of Transportation at Montgomery, Alabama 36110.
In accordance with the rules and regulations of The Alabama Department of Transportation, proposals will be issued only to prequalified contractors or their authorized representatives, upon requests that are received before 10 AM., on the day previous to the day of opening of bids. The bidder’s proposal must be submitted on the complete original proposal furnished him or her by the Alabama Department of Transportation.
The Alabama Department of Transportation, in accordance with Title VI of the Civil Rights Act of 1964, 78 Stat. 252, 42 U.S.C. 2000D TO 2000D-4 and Title 49 code of Federal Regulations, Department of Transportation, Subtitle A, Office of The Secretary, Part 21, nondiscrimination in federallyassisted programs of the Department of Transportation issued pursuant to such act, hereby notifies all bidders that it will affirmatively insure that in any contract entered into pursuant to this advertisement, minority business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, religion, sex, or national origin in consideration for an award.
The right to reject any or all bids is reserved.
JOHN R. COOPER
Transportation Director
5-11-3c
Legal Notice
MORTGAGE FORECLOSURE SALE.
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Jamie Hammond, a single woman, originally in favor of Mortgage Electronic Registration Systems, Inc., acting solely as nominee for First Federal Bank, on July 9, 2010, said mortgage recorded in the Office of the Judge of Probate of Hale County, Alabama, in Book 0365 Page 0364; being modified by Loan Modification Agreement in MORTGAGE Book: 2017 Page: 140; the undersigned Lakeview Loan Servicing, LLC, as Mortgagee/ Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Greensboro, Hale County, Alabama, on May 30, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Hale County, Alabama, to-wit:
Lots 11 and 12 Park Manor Subdivision, a map or plat of which is recorded in Map Book 2, at Page 7 in the Probate Office of Hale County, Alabama.. Property street address for informational purposes: 137 Park Manor , Moundville, AL 35474. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
Lakeview Loan Servicing, LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223 www.tblaw.com TB File Number: 22-09901 05/11/2023, 05/18/2023, 05/25/2023 5-11-3c
